1998_0824_packet - Laserfiche WebLink

Home

be in accordance with the Construction Industry Arbitration Rules of the American Arbitration Association currently-in effect.The demand for arbitration shall be filed in writing Nvith the other arty to this Agreement and with the An-ierican Arbitration Association. 7.2.3 A demand for arbitration shall be made within a reasonable time after the claim}dispute or other matter in question has' arisen. In no event shall the demand for arbitration he made after the date when institution of legal or equitable proceedings based on such claim,dispute or other natter in question would be barred by the applicable statute of liniitationw. T2.4 No arbitration arising out of or relating to this.agreement shall include,by consolidation or joinder or in an� other manner,an additional person or entity not a part-to this Agreenica, e ce t h� �rri tten consent containing a s pec i f c re fere��ce to this Au ree ment and sic ed l�}F the 1 r Darner, Architect, and any other person or entity sOught to be joined. Consent to arbitration im,olving an additional person or entity shall not constitute consent to arbitration of any claim, dispute or other natter in question not described in the written consent or Nvith a person or enti t not named or described therein.The foregoing agreement to arbitrate and other agreements Y to arbitrate with an additional person or entity duly consented to by parties to this Agreement shall be specifically enforceable in accordance with applicable la%v in any court having jurisdiction thereof. 7.2.5 The aNvard rendered by the arbitrator or arbitrators shall he final, and lud g m e nt may be entered upon it in accordance with applicable lave in any court having jurisdiction thereof. 7.3 CLAIMS FOR CONSEOUENTIAL DAMAGES The Architect and Owner waive consequential damages for claims, disputes or other matters i n question arising out of or relating to this Agreement. This mutual waiver is applicable,without limitation, to all consequencial damages due to either party}s termination in accordance with Article 8. ARTICLE 8 TERMINATION OR SUSPENSION 8.1 If the Owner fails to make payments to the Architect in accordance with this Agreement, such failure shall be considered substantial nonperformance and cause for termination or,at the Architect's option,cause for suspension of performance of services under this Agreement. If the Architect elects to suspend services,prior to suspension of services,the architect shall give seven da s'written notice to the Owner.In the event of a suspension of services,the architect shall have no ser liability to the Owner for delay or damage caused the Owner because of such suspension of vices.Be r fore resumin g services,the Architect shall be paid all sums due prior to suspension and expenses incurred in the in and resumption of the Architects services. The any ex'p Architect's fees for the remaining services and the time schedules shall be equitably adjusted. 8.2 If the Project is suspended by the Owner for more than 30 consecutive days,the Architect shall be compensated for services performed prior to notice of such suspension.When the project is resumed, the Architect shall be compensated for expenses incurred in the interruption and resumption of the Architect's services.The Architect's fees far the remaining services and the time p � schedules shall be equitably adjusted. � the Project is suspended or the Architect's ser-ices are suspended for more than o '9 �' �' �. If 1 1 , AIA DOCUMENT 6151-1997 he architect may terminate this Agreement by giving not less than seven days consecutive days,t ABBREVIATED OWNER- written notice. ARCHITECT AGREEMENT terminated b either art upon not less than seven days'written The American Institute 8.4 This agreement may be#. ' party P this Architects -e should the other art fail substantially to perform in accordance with the terms of th 1735 New York Avenueo N.W. notice party u h no fault of the arty initiating the termination. Washington,D.C.2oo -5292 Agreement thro g l