pf_01677 - Laserfiche WebLink

Home

�I 11 11 1] 'j 1] 11 t Al �J r 1- 1 separate contracts in connection with other portions of the Project or other work on the site under these or similar Conditions of the Contract. If the Contractor claims that delay or additional cost is involved jecause of such action by the Owner, he shall make such claim as pro- vided elsewhere in the Contract Documents. 6.1.2 When separate contracts are awarded for different portions of the Project or other work on the site, the term Contractor in the Contract Documents in each case shall mean the Contractor who executes each separate Owner - Contractor Agreement. 6.1.3 The Owner will provide for the coordination of the work of his own forces and of each separate contractor with the Work of the Contractor, who shall cooperate therewith as provided in Paragraph 6.2. 6.2 MUTUAL RESPONSIBILITY 6.2.1 The Contractor shall afford the Owner and separate contractors reasonable opportunity for the introduction and storage of their materials and equipment and the execution of their work, and shall connect and coordinate his Work with theirs as required by the Contract Docu- ments. 6.2.2 If any part of the Contractor's Work depends for proper execution or results upon the work of the Owner or any separate contractor, the Contractor shall, pr4o7.- to proceeding with the Work, promptly report to the Archi- tect any apparent discrepancies or defects in such other work that render it unsuitable for such proper execution and results. Failure of the Contractor -o to report shall constitute an acceptance of the Owner , or separate con- tractors* work as fit and proper to receive his Work, ex- cept as to detects which may subsequently become appar• rent In such work by others, 6.2.3 Any costs caused by deiective or ill-timed work shall be borne by the party responsible therefor. 6.2.4 Should the Contractor wrongfully cause damage to the work or property of the Owner. or to other work on the site. the Contractor shall promptly remedy such dam• age as provided in Subparagraph 10 2.5, 6.2.5 Should the Contractor %vrongiully cause damage to the wofk or property oi any separate contractor, the Con• tractor shall upon due notice promptly attempt to settle with such other contractor by agreement, or otherwise to resolve the dispute, If such separate contractor sues or ,nitrates an arbitration proceeding against the Owner on account of any, damage alleged to have been caused by the Contractor, the Owner shall notify the Contractor shall delend iuch pioceeding5 -it the Ownet'} e�- nense, and if any judgment or award against the Owner arises therefrom the Contractor shall pay or satisfy it and shall reimburse the Owner for all attorneys' fees and court or arbitration costs which the 0• net has incurred. 6,3 OWNER'S RIGHT TO CLEAN UP 6.3.1 If a dispute arises between the Contractor and sepa- rate contractors a5 to their responsibility for cleaning up as required by Paragraph 4.15, the Owner may clean up and charge the cost thereof to the contractors responsible therefor as the Architect shall determine to be just. ARTICLE 7 MISCELLANEOUS PROVISIONS 7.1 GOVERNING LAW 7.1.1 The 'Contract shall be governed by the law of the place where the Project is located. 7.2 SUCCESSORS AND ASSIGNS 7.2.1 The Owner and the Contractor each binds himself, his partners, successors, assigns and legal representatives to the other party hereto and to the partners, successors, assigns and legal representatives of such other party with re- spect to all covenants, agreements and obligations con- tained in the Contract Documents. Neither party to the Contract shall assign the Contract or sublet it as a whole without the written consent of the other, nor shall the Contractor assign any moneys due or to become due to him hereunder. without the previous written consent of the Owner. 7.3 WRITTEN NOTICE 7.3.1 Written notice shall be deemed to have been duly served If delivered In person to the individual or member of the firm or entity or to an officer of the corporation for whom It was intended, or it delivered at or sent by regis- tered or certified mail to the last business address known to him who gives the notice. 7.4 CIAIMS FOR DAMAGES 7,4.1 Should either party it) the Contract suffer injury or damage to person or property because of any act or omis- sion of the other party or of any of his employees, agents or others for whose acts he is legallyl liable, clairn shall be made in writing to such other party within a reasonable time after the first observance oaf such injury or damage. 7,3 PERFORMANCE BOND AND LABOR AND MATERIAL PAYMENT BOND 7.5.1 The Owner shall have the right to require the Con- tractor to furnish bonds covering the iailhiul performance of Contract and the payment of all obligations arising thereunder if and as required In the Bidding Documents or in the Contract Document#. 7,6 RIGHTS AND REMEDIES 7.6.1 The duties and obligations imposed by the Contract Cocuments and the rights and remedies available there- uneter shall be ?n addition to and not a limitation of any duties. obligations, rights and remedies otherwise im- posed or available by law, 7.6.2 1114o action or failure to act by the Owner, Architect or Contractor shall constitute a waiver of any right or duly anorded any of them under the Contract, nor shall any such action or failure to act constitute an approval of or acquiescence in any breach thereunder, except as may be specifically agreed in writing, AIA DOCUMENT A201 • GENERAL CON0I7IONS OF THE CONTRACT FOR CONSTRUCTION . THIRTEENTH EDITION • AUGUST 1976 AIAS . cp IQ76 . THE AmERICAN INSTITUTE OF ARCHITECTS, I']$ NEW YORK AVENUE, `r %V WASHINGTON, D,C. 2m A201.1976 11