§ 1.2.2.2 The Owner shall periodically update the budget for the Project,, including that portion allocateld for thie Cost
<br />of the Work. The Owner shall not significantly increase or decrease [hie overall 'budgiet,thie po1iion, of tile, budgiet
<br />I
<br />allocated for the Cost of the Work, or contingencies included in tile overall budget or a portion of the budget,
<br />without the agreement of the Engineer to a corresponding change in the Project scope and quality.
<br />§ 1.2.2.3 The Ownex's Designated Representative • identified in Section 1 13 shall be authorized to act on the
<br />Owner's behalf with respect to the Project, The Owner or the Owner's Designated Representative shall render
<br />decisions in a tiniely inanner pertaining to doouments sub"Utted by the Engineer in order to avoid unreasonable
<br />delay in the orderly and sequential progress of the Engineer's services.
<br />§ 1.2.2.4 The Owner shall furnish the services of consultants other than those designated in Seictilioll l or authorize
<br />the Engineer to farnish thern as a Change in Services when such services a requested by the Engineer and are
<br />reasonably required by the scope of tile Project.
<br />§ 1,2.2.5 Urfless otherwise provided in this Aerreenient, the Owner shall furnish tests, inspections and reports required
<br />rl*p
<br />by law or the Contract Documents, such as structural, mechanical, and chen-tical tests, tests for air and water
<br />pollution, and tests for hazardous materials.
<br />§ 1.2.2.6 The Owner shall furnish all legal, insurance and accounting servicies, including auditing, services, that may
<br />be reasonably necessary at any time 'or the Project to Ineet the Owners nieedsand interests., Nothing herein shall be
<br />construed to require the Owner to defend or indenuiffy the Engincier for the Engineer" s own ne,gligrenice, rrialpractioe
<br />or intentional acts.
<br />§ 1.2.2.7 The Owner shall provide prompt written notice to the Engineer if the Owner becomes aware, of any fault or
<br />defect in the Project, including any eff ors, on- fissions car inconsisten cies in the Engineer's Instruments of Service.
<br />§ 1.2.3 ENGINEER
<br />§ 1.2.3.1 The services performed by the Engineer, Engineers employees and Engineer's consultants shall be as
<br />enumerated in Article 1.4.
<br />§ 1.2.3.2 The Engineer's services shall be performed as expeditiously as is consistent with professional skill and care
<br />and the orderlypTOgress of the Project. The Engineer shall submit for the Owner's, apprioval a schedule for the
<br />performance of the Engineer's services which initially shall be consistent with the time periods established in
<br />Section 1. 1.2.6 and which shall be adjusted, if necessary, as the Project pro�iceeds. This schedule shall include
<br />allowances for periods of time required for the Owner's review, for the performance of the Owner's consultants, and
<br />for approval of submissions by authorities having jurisdiction over the Project. Time limits established by this,
<br />schedule approved by the Owner shall not, except for reasonable, cause, be exceeded by the Engineer or Owner,.
<br />§ 1.2.3.3 The Engineer's Designated Representative identified in S, ection, 1..1.3 shall be authorized to ;act on the
<br />Engineer's behalf with respect to the Project.-
<br />§ 1.2.3.4 The Engineer shall maintain the confidentiality of information specifically designated as confidential by the
<br />Owner, unless withliolding such information would violate the law, create, the risk of'significant harm to, the public
<br />or prevent the Engineer from establishing a claim or defense, in an adjudicatory proceeding. The Engineer shall
<br />require of the Engineer's consultants similar agreements to maintain the confidentiality of information specifically
<br />designated as confidential by the Owner.
<br />§ 1.2.3.5 Except with the Owner's knowledge and consent, the Engineer shall not engage, in any alictivity, or accept
<br />any employment, interest or contribution that would reasonably appear to compromise the engineer's professional
<br />judgment with respect to this Project.
<br />1.23.6 The En ineer shall review laws, codes, and regulations applicable to the Engineer's, services. The Engineer
<br />91
<br />shall respond in the design of the Project to requirements imposed by govenmiental authorities having jurisdiction
<br />over the Project.
<br />. ...... 1948o 1951, 1 �953, 1958. 19611 1 1963,,t 1966,119167,119710, 19741,11977, 1987 and 1997 by The
<br />Init. Al A Document B141rm -1997 Part 1, Copyright 01917, 19261 ISI Copyright Law and International Treaties, 4
<br />American tnStitute of Architects. All rights reserved. WARNING: This AIA Document is protiectedi �by� US,
<br />Unauthorized reproduction or distribution of this Ale Document, or any portion u f it, may riesult in severe, civil anild criminial pienalties, and will be
<br />prosecuted to the maximum extent possible under the law. This document was pr�iod�uced by AIA sloillwarle iat 107:141 :2119 on 02105/2008, under Order
<br />a k �,J "; .-s4.1 -
<br />NO. 10 0 003 2`7144*2 1 -whic 111 Q ^,, r deks, 0"11 11, /r.,41-0 0108, and i,.q not for resale. - %
<br />User Notes:
<br />
|